1 2 3 4 UNITED STATES DISTRICT COURT 5 NORTHERN DISTRICT OF CALIFORNIA 6 SAN JOSE DIVISION 7 8 KJ-PARK, LLC, Case No. 23-cv-02346-VKD

9 Plaintiff, ORDER RE PARTIES' MOTIONS FOR

SUMMARY JUDGMENT AND

10 v. DENYING AS MOOT CERTAIN

MOTIONS TO EXCLUDE EXPERT

11 MATCH GROUP, LLC, et al., TESTIMONY 12 Defendants. Re: Dkt. Nos. 97, 99, 100, 104

13 14 This federal diversity action arises out of a commercial lease agreement for a three-story 15 building located at 2555 Park Boulevard in the City of Palo Alto, California (“City”).1 Plaintiff 16 KJ-Park, LLC (“KJ-Park”) claims that defendants Match Group, LLC and Match Group, Inc. 17 (collectively, “defendants” or “Match Group”) breached the lease agreement and a guaranty, and 18 owe KJ-Park at least $6,986,605 in damages, plus additional unpaid rent. See Dkt. No. 72. The 19 key disputed issue is whether Match Group properly terminated the lease agreement. 20 KJ-Park now moves for partial summary judgment on its claims and on Match Group’s 21 affirmative defenses of mistake, fraud in the inducement, illegal purpose, and frustration of 22 purpose. KJ-Park principally contends that it obtained a “vested legal right” to use the entire 23 three-story building as an office well before the parties entered into the lease agreement, 24 regardless of any position to the contrary asserted by the City, and that Match Group therefore had 25 no right to terminate the lease agreement on the basis that KJ-Park failed to deliver premises that 26

27 1 All parties have expressly consented that all proceedings in this matter may be heard and finally 1 complied with the City’s retail ordinance. Dkt. Nos. 100, 114. Match Group opposes KJ-Park’s 2 motion for partial summary judgment. Dkt. No. 106. 3 Match Group also moves for summary judgment in its favor on KJ-Park’s claims for 4 breach of contract and breach of guaranty, as well as Match Group, LLC’s counterclaims for 5 breach of contract and for monies had and received, and Match Group’s affirmative defenses of 6 mistake and frustration of purpose. Match Group contends that the City applied its retail 7 ordinance to preclude or delay approval for the lawful occupancy and use of the subject property 8 as office space on all three floors until well after KJ-Park was contractually obliged to deliver the 9 premises to Match Group. Match Group, LLC claims that KJ-Park owes more than $300,000 for 10 rent, expenses, vendor costs, and security regarding the subject property. Dkt. Nos. 97, 113. KJ- 11 Park opposes Match Group’s summary judgment motion. Dkt. No. 107. 12 Upon consideration of the parties’ respective moving and responding papers, as well as the 13 oral arguments presented, the Court grants in part and denies in part KJ-Park’s motion for partial 14 summary judgment, and grants in part and denies in part Match Group’s motion for summary 15 judgment.2 16 I. BACKGROUND 17 Unless otherwise indicated, the following facts are undisputed. 18 In September 2013, a prior property owner submitted an application to the City for 19 permission “to [a]llow the [d]emolition of an [e]xisting 10,800 sq. ft. [t]wo-[s]tory [m]id-[c]entury 20 [m]odern [o]ffice [b]uilding and [c]onstruction of a [n]ew 24,466 sq. ft. [t]hree-[s]tory [o]ffice 21 [b]uilding,” with “[o]ne [l]evel of [b]elow [g]rade [p]arking and a [r]oof [t]errace . . . [l]ocated in 22 the Community Commercial (CC(2)) [z]one [d]istrict at 2555 Park Boulevard.” Dkt. No. 101 ¶ 8, 23 Ex. F at ECF 2, 3, 4, 7, 9, 10, 12-13; Dkt. No. 101 ¶ 5, Ex. C (Reich Dep. at 26:4-11). On October 24 2 In view of the rulings in this order, the Court finds it unnecessary to address the parties’ Daubert 25 motions regarding Mr. Owyang and Mr. Fronen, who offer opinions on KJ-Park’s claimed damages. Dkt. Nos. 99, 104. Accordingly, those motions are denied as moot. The Court will 26 issue a separate order on Match Group’s motion to exclude the testimony of Erik Schoennauer. Dkt. No. 98. As discussed in that separate order, the Court’s rulings regarding Mr. Schoennauer’s 27 opinions do not change the Court’s analysis or conclusions regarding the disposition of the parties’ 1 16, 2014, after reviewing the application, the City’s Architectural Review Board recommended 2 that the City Council approve the project. See Dkt. No. 101 ¶ 5, Ex. C (Reich Dep. at 30:10- 3 31:24) & Ex. E; see also generally id. ¶ 3, Ex. A (Lait Dep. at 36:18-40:15). An Environmental 4 Impact Report was also prepared and considered. See Dkt. No. 101 ¶ 8, Ex. F at ECF 95-223. 5 On June 1, 2015, the City Council approved a Record of Land Use Action (“RLUA”) 6 “certify[ying] the Environment Impact Report,” and “approv[ing] the Architectural Review for a 7 three story office building in the Community Commercial (CC(2)) zone district[.]” See Dkt. No. 8 101 ¶¶ 8-10, Exs. F-H; see also id. ¶ 3, Ex. A (Lait Dep. at 41:3-14, 47:7-49:4, 51:5-15). The 9 RLUA granted a one-year term of approval, or entitlement, with respect to the project through 10 June 1, 2016. Id. ¶ 9, Ex. G at ECF 33. The RLUA stated that “[i]n the event actual construction 11 of the project is not commenced within one year of the date of council approval, the approval shall 12 expire and be of no further force or effect pursuant to the [City Municipal Code].” Id. Jonathan 13 Lait, the City’s current Director of Planning and Development Services,3 testified in deposition 14 that the RLUA documented the City’s findings that the proposed project met applicable standards 15 in the zoning code, “allows offices to be built in this building,” and “authorizes the office to be 16 located at the building,” while “the land uses that go into that building would be subject to the 17 permitted land uses of the zoning code.” Dkt. No. 101 ¶ 3, Ex. A (Lait Dep. at 52:16-23; 53:6-7, 18 15-16; 53:23-54:9). While Mr. Lait further testified that the RLUA was the last discretionary 19 approval required for “the building shell and design,” the RLUA itself required the property owner 20 to apply for a building permit. Dkt. No. 101 ¶ 3, Ex. A (Lait Dep. at 48:9-12, 16-23); Dkt. No. 21 101 ¶ 9, Ex. G at 9. 22 The RLUA’s “Conditions of Approval” include a requirement by the City’s Department of 23 Planning and Community Development that the property owner submit plans for a building permit 24 “in substantial conformance with the plans received on October 16, 2014, except as modified to 25 incorporate the [Conditions of Approval], and any additional conditions placed on the project by 26 3 Mr. Lait began working for the City as the Assistant Director of Planning and Development 27 Services in September 2014. He became the Director of that department around February 2019; 1 the Planning Commission, Architectural Review Board, or City Council.” Dkt. No. 101 ¶ 9, Ex. G 2 at 9. According to Mr. Lait, this section meant that “any substantial changes to the project may 3 require additional discretionary action review,” and that “the project can’t change substantially 4 from what was approved.” Dkt. No. 101 ¶ 3, Ex. A (Lait Dep. at 51:19-52:8). The RLUA also 5 contains an “Additional Conditions” provision and a separate “Standard Conditions” section, 6 which both state, “The approved use and/or construction are subject to, and shall comply with, all 7 applicable City ordinances and laws and regulations of other governmental agencies.” Dkt. No. 8 101 ¶ 9, Ex. G at ECF 32, 34. 9 Several months later, the City Council passed Ordinance No. 5358 (“Ordinance”), which 10 amended retail zoning regulations for the CC(2) zoning district, where the subject Park Boulevard 11 property is located. See Dkt. No. 97-1 ¶ 4, Ex. 3. The Ordinance went into effect on November 12 26, 2015 and essentially requires retail use on the ground floor of buildings within the zoning 13 district. See id.; see also Dkt. No. 97-1 ¶ 7, Ex. 6 (Lait Dep. at 121:18-22, 176:8-12). The 14 Ordinance provides that “[l]awful conforming permitted uses or conditional uses operating 15 pursuant to a conditional use permit which were existing on April 26, 1984 may remain as 16 grandfathered uses and shall not require a conditional use permit or be subject to the provisions of 17 [Municipal Code] Chapter 18.70 [concerning “Nonconforming Uses and Noncomplying 18 Facilities”].” Dkt. No. 97-1 ¶ 4, Ex. 3. Otherwise, the Ordinance provides for a request for 19 “waiver or adjustment” of the Ordinance, which would require action by the City Council:

20 (a) Economic Hardship. An applicant may request that the requirements of this Ordinance be adjusted or waived only upon a 21 showing that applying the requirements of this Ordinance would effectuate an unconstitutional taking of property or otherwise have 22 an unconstitutional application to the property.

23 (b) Documentation. The applicant shall bear the burden of presenting substantial evidence to support a waiver or modification 24 request under this Section and shall set forth in detail the factual and legal basis for the claim, including all supporting technical 25 documentation. Any request under this section shall be submitted to the Planning and Community Environment Director together with 26 the fee specified in the municipal fee schedule and an economic analysis or other supporting documentation. A request under this 27 section shall be acted upon by the City Council. 1 KJ-Park purchased the subject property in August 2016, more than eight months after the 2 Ordinance went into effect. Dkt. No. 102 ¶ 2. KJ-Park was aware of the Ordinance since at least 3 March 2016, when the prior property owner provided KJ-Park with information about the 4 Ordinance. See Dkt. No. 97-1 ¶ 19, Ex. 18. 5 On May 27, 2016, about two months prior to KJ-Park’s purchase of the property, the City 6 approved a one-year extension of the RLUA for the project, giving KJ-Park until June 1, 2017 to 7 begin construction. See Dkt. No. 102 ¶ 6, Ex. 2; see also id. ¶ 7, Ex. 3. The extension noted that 8 “the original findings and conditions for this project are still applicable, as indicated in the 9 [RLUA].” Dkt. No. 102 ¶ 6, Ex. 2. The record presented does not indicate whether the request for 10 the extension referred to the Ordinance or its potential application to the subject property or 11 project. The City’s letters confirming the extension do not contain any such language. See id. 12 ¶¶ 6, 7, Exs. 2, 3. 13 On November 16, 2016, the City’s Planning Department advised that KJ-Park’s building 14 permit was in “ready to issue” status. On that same day, KJ-Park paid the City $478,705.17 in 15 development impact fees. Dkt. No. 102 ¶ 8, Exs. 4, 5. 16 In January 2017, KJ-Park applied for a building permit and paid an additional $149,202.78 17 in permit fees. Dkt. No. 102 ¶ 9, Ex. 6. On January 19, 2017, the City issued a building permit 18 for a “N[ew] W[arm] S[hell] F[or] T[hree] S[tory] C[ommercial] 23,853 S[quare] F[oot] 19 B[uilding], A[nd] B[elow] G[rade] P[arking] S[tructure].” Id. The permit itself did not include 20 any discussion of, or requirements for, the building’s use. Id. Russell Reich, the City’s project 21 planner, testified in deposition that the term “warm shell” refers to a “building without the interior 22 tenant spaces built out” and no “specific occupancy.” Dkt. No. 106-1, Ex. 9 (Reich Dep. at 23 104:15-21). The record presented does not contain any testimony to the contrary. 24 On February 14, 2017, Dan Minkoff of The Minkoff Group (KJ-Park’s project manager) 25 sent an email to Mr. Reich, inquiring whether Mr. Reich “had a chance to look into the 26 applicability of the retail ordinance that was passed after the project was approved[.]” Dkt. No. 27 101 ¶ 12, Ex. J at ECF 2. Mr. Reich responded that same day, stating that he “discussed this with 1 ground floor.” Id.; see also Dkt. No. 101 ¶ 3, Ex. A (Lait Dep. at 82:18-23); Dkt. No. 101 ¶ 5, Ex. 2 C (Reich Dep. at 65:5-21). In deposition, Mr. Reich confirmed that he shared Mr. Lait’s view on 3 that issue. Dkt. No. 101 ¶ 5, Ex. C (Reich Dep. at 65:19-21). 4 KJ-Park subsequently submitted revised plans for cosmetic changes to the building’s 5 façade, which the City’s Architectural Review Board approved in April 2017. Dkt. No. 101 ¶ 5, 6 Ex. C (Reich Dep. at 26:19-27:21); ¶ 14, Ex. L. KJ-Park’s building plans otherwise remained the 7 same as those approved by the RLUA. See id. ¶ 14, Ex. L; see also Dkt. No. 103 ¶ 9, Ex. B. 8 On October 26, 2018, KJ-Park and Match Group, LLC executed an Office Lease (“Lease”) 9 for the subject property. Dkt. No. 97-1 ¶ 2, Ex. 1. Match Group, Inc. concurrently executed a 10 Guaranty of Lease (“Guaranty”) in which Match Group, Inc. guaranteed all of Match Group, 11 LLC’s obligations under the Lease. Dkt. No. 97-1 ¶ 3, Ex. 2. 12 As relevant here, the Lease provided that KJ-Park would:

13 construct or shall cause the construction of, at its sole cost and expense, the base, shell, and core of the Building, which base, shell, 14 and core shall be in compliance with Applicable Law (to the extent necessary for Tenant to obtain and retain a certificate of occupancy 15 or its legal equivalent for the Premises for general office use) and in compliance with Section 510 of the City of Palo Alto Code 16 (collectively, the “Base, Shell and Core” and such work to be known as the “Landlord Work”). 17 18 Dkt. No. 97-1 ¶ 2, Ex. 1 at ECF 52 (emphasis added). The Lease expressly provided that 19 “[n]otwithstanding anything contained herein to the contrary, any retail or restaurant use that 20 serves the general public is not permitted.” Id. at ECF 14. 21 The Lease was for a term of 87.5 months from the “Delivery Date,” which is defined by an 22 appended Tenant Work Letter as “[t]he date upon which Landlord delivers (or is deemed to have 23 delivered) possession of the Premises to Tenant in Delivery Condition[.]” Id. at ECF 2, 52. The 24 Lease further provides that “Delivery Condition” means:

25 [t]he Base, Shell and Core for the Premises being in a construction- ready condition, which condition shall mean the substantial 26 completion of the items set forth on Schedule 1, attached hereto, and Landlord shall have delivered to tenant an AIA Form G704 27 Certificate of Substantial Completion with regard to the Landlord Hazardous Materials (if any) below appropriate screening levels. 1 2 Id. at ECF 52. As used in the Lease, the term “Applicable Laws” refers to “any law, statute, 3 ordinance or other governmental rule, code, regulation or requirement now in force or which may 4 hereafter be enacted or promulgated, including any such governmental regulations related to 5 disabled access[.]” Id. at ECF 36. With respect to the Delivery Date, section 2.3 of the Lease also 6 provided: 7 2.3 Delivery Date; Delayed Delivery Date. Landlord shall 8 deliver possession of the Premises to Tenant on the Delivery Date; provided, however, that if the Delivery Date is delayed due to any 9 acts or omissions of Tenant or any other Tenant Parties (each such delay, a “Tenant Delay”), then the Delivery Date shall be deemed 10 to have occurred on the date that it would have occurred by for such Tenant Delay. Notwithstanding any provision of this Lease to the 11 contrary, if the Delivery Date shall not occur on or before March 1, 2019 (which date shall be extended by the number of days of any 12 Tenant Delays and Force Majeure), then until the Delivery Date occurs (i) the period of 3.5 calendar months set forth in Section 4 of 13 the Summary (i.e., the Rent Abatement Period) shall be extended by an additional number of days equal to one day for each day after 14 March 1, 2019 until the Delivery Date and (ii) Tenant shall have the right to terminate this Lease, by notice to Landlord on or before the 15 15th day following the Delivery Date, whereupon this Lease shall terminate, and Landlord and Tenant shall have no further 16 obligations or liabilities under this Lease (other than those stated in this Lease to survive the expiration date) except Landlord shall 17 promptly return to Tenant any rent, additional rent or security paid by Tenant to Landlord. 18 19 Id. at ECF 8 (emphasis added). 20 Match Group says that at the time defendants entered into the Lease, they had no 21 knowledge of the Ordinance. See Dkt. No. 97-1 ¶ 6, Ex. 5 (Perez Dep. at 83:19-21, 84:6-7). In 22 deposition, KJ-Park’s principal, John Fong, testified that he could not recall, one way or the other, 23 whether during contract negotiations KJ-Park informed Match Group about the Ordinance. See 24 Dkt. No. 97-1 ¶ 9, Ex. 8 (Fong Dep. at 90:12-18; 91:1-4). 25 On March 20, 2019, Match Group, LLC’s architect and general contractor met with the 26 City’s Planning & Development Department to discuss Match Group, LLC’s forthcoming 27 application for tenant improvements. Match Group, LLC’s tenant improvement plan 1 Dkt. No. 97-1 ¶ 11, Ex. 10 at ECF 5-6. At that meeting, Garrett Sauls, a City Associate Planner, 2 noted the Ordinance as an issue for the tenant improvement application. See id. 3 On March 28, 2019, KJ-Park obtained the City’s final inspections and approvals for the 4 base, shell, and core of the subject property. See Dkt. No. 97-1, ¶ 20, Ex. 19 at ECF 3; see also 5 Dkt. No. 101 ¶ 19, Ex. Q at ECF 3. 6 Meanwhile, Match Group, LLC experienced delay in its tenant improvement application, 7 while Mr. Sauls and other City staff attempted to ascertain whether retail use would be required on 8 the ground floor of the subject property. See Dkt. No. 97-1, ¶ 11, Ex. 10 at ECF 1-5; id. ¶ 8, Ex. 7 9 (Sauls Dep. at 88:23-90:4; 93:1-9); id. ¶ 12, Ex. 11 at ECF 2; id. ¶ 20, Ex. 19. KJ-Park assured 10 Match Group that it was “working on this issue to help get this resolved ASAP,” advised that KJ- 11 Park had a meeting with City officials on April 9, 2019, and encouraged Match Group, LLC to 12 apply for its permit, noting that “the City is quite slow and the sooner you can get in the cue [sic] 13 the better it’ll be to get your project processed and through the system.” Dkt. No. 110 ¶ 30, Ex. 21 14 at ECF 3. Match Group, LLC responded that it “did submit [its] drawings for permit to get in the 15 queue,” but noted that the City required “a sizable non-refundable plan check fee to begin their 16 review,” and Match Group, LLC “did not want to submit the payment without knowing if we will 17 be able to proceed as currently designed or not.” Id. 18 On April 11, 2019, Match Group, LLC’s broker emailed Mr. Sauls and other City staff, 19 asking “Could we submit our [tenant improvement] drawings now? Or do we need resolution 20 with the 1st floor retail requirement before submittal?” Dkt. No. 97-1 ¶ 20, Ex. 19 at ECF 8. Mr. 21 Sauls responded, “I would not recommend that you resubmit your plans until we can get 22 clarification about the retail requirements for the space,” noting that he would “check in with the 23 Director [Jonathan Lait] to see what is going on with the project.” Id. In an email to Match 24 Group, LLC’s broker later that day, Mr. Sauls confirmed, “The director agrees that you should 25 wait until the issue is addressed. They are looking to close the loop on the conversations with the 26 City manager and City attorney’s office soon[.] At that point, we will all know what the direction 27 will be.” Id. at ECF 2. 1 representatives held a “big all-hands” conference call, during which he recalls they discussed 2 “[g]enerally that progress is being made with the [C]ity and that a resolution should be coming 3 soon.” Dkt. No. 116 ¶ 4, Ex. B (Fong Dep. at 185:16-187:23); see also id. ¶ 5, Ex. C. Notes from 4 a Match Group internal “Real Estate Update” meeting state “Update 5/24/19: (1) Hopeful for 5 decision from City post Memorial Day wkd.” Id. ¶ 3, Ex. A at ECF 6. 6 Match Group says that after waiting more than two months without confirmation from the 7 City whether the subject property could be used as office space on all three floors (and no retail 8 use), Match Group terminated the Lease on May 30, 2019. Match Group’s termination letter to 9 KJ-Park stated that defendants were terminating the Lease, effective immediately, pursuant to 10 Section 2.3 of the Lease. Dkt. No. 97-1 ¶ 18, Ex. 17. The termination letter further explained, in 11 relevant part:

12 In order for the Delivery Date and, therefore, the Lease Commencement Date, to occur (1) the Base, Shell and Core must be 13 in compliance with all Applicable Law to the extent necessary for us to obtain a certificate of occupancy for the Premises for general 14 office use and (2) you must have delivered to us possession of the Premises in that condition. 15 The undisputed facts are that . . . as of today’s date, you 16 have not placed the Base, Shell and Core in the condition for us to obtain a certificate of occupancy for the Premises for general office 17 use, evidenced by the City’s position that the ground floor portion of the Premises must be used for retail purposes and cannot be used for 18 general offices. . . .

19 It is, therefore, beyond question that you have failed to comply with the requirements of the Lease for the Delivery Date 20 and, therefore, the Lease Commencement Date, to have occurred.

21 Accordingly, pursuant to Section 2.3 of the Lease, we hereby terminate the Lease, effective immediately. Please promptly return 22 any rent, additional rent or security. 23 Id. 24 Match Group maintains that there was no resolution of the issue regarding retail use on the 25 ground floor of the subject property until June 4, 2019. Specifically, Match Group says that 26 following an undisclosed threat of litigation by KJ-Park against the City, the City Council 27 convened a Special Meeting on June 3, 2019. See Dkt. No. 97-1, ¶ 14, Ex. 13 at ECF 2. The City 1 results of which are documented in the City Council’s minutes as follows:

2 Mayor Filseth announced the Council voted 6-1 (Council Member Kou dissenting) to approve an agreement between the City and the 3 property owner at 2555 Park Boulevard to resolve a potential lawsuit with an agreement that retail use shall not be required on the 4 ground floor of the building at 2555 Park Boulevard and that the office use on the ground floor shall be considered a legal 5 nonconforming use. 6 Id. at ECF 10. KJ-Park and the City also entered into a Settlement and Mutual Release Agreement 7 “to avoid the cost, difficulty and uncertainty of litigation and to finally settle and resolve their 8 disagreements regarding the application of Ordinance 5358 to the [subject property].” Dkt. No. 9 97-1 ¶ 5, Ex. 4 at ECF 3. The settlement agreement states the City’s agreement “that retail use 10 shall not be required on the ground floor of the Project, and that the office use on the ground floor 11 of the Project shall be considered a legal nonconforming use, subject to the provision of Palo Alto 12 Municipal code Chapter 18.70, as if established prior to the effective date of Ordinance 5358.” Id. 13 The settlement agreement further states that the City “agrees to review and process the application 14 for tenant improvements at the Project promptly following full execution of this Agreement.” Id. 15 But, as discussed above, Match Group claims that it had already terminated the Lease on May 30, 16 2019. Dkt. No. 97-1 ¶ 18, Ex. 17. 17 On March 23, 2023, K-J Park filed the present lawsuit against Match Group in the Santa 18 Clara County Superior Court, claiming that Match Group breached the Lease and Guaranty. Dkt. 19 No. 1-2. Match Group removed the action to this Court, asserting federal diversity jurisdiction, 28 20 U.S.C. § 1332. See Dkt. No. 1; see also Dkt. Nos. 22, 22-1. Following KJ-Park’s sale of the 21 subject property in October 2023, the Court gave KJ-Park leave to file an amended complaint to 22 lower the amount of its claimed damages.4 Dkt. No. 70. KJ-Park’s operative first amended 23 complaint seeks at least $6,986,605, plus “unpaid additional rent in an amount to be proven,” 24 interest, attorneys’ fees, and costs. Dkt. No. 72. In their answer, defendants assert affirmative 25 defenses based on unilateral mistake (third affirmative defense), mutual mistake (fourth 26

27 4 The Court denied KJ-Park’s request to amend its complaint to add a claim for breach of the 1 affirmative defense), fraud in the inducement (sixth affirmative defense), illegal purpose (seventh 2 affirmative defense), and frustration of purpose (eleventh affirmative defense). Dkt. No. 76. 3 Additionally, Match Group, LLC asserts counterclaims for breach of contract and for monies had 4 and received, claiming that KJ-Park owes Match Group, LLC more than $300,000, representing 5 amounts that Match Group, LLC paid for rent, expenses, vendor costs, and security regarding the 6 subject property. Id. 7 KJ-Park now moves for partial summary judgment on its claims5 and on Match Group’s 8 affirmative defenses of mistake, fraud in the inducement, illegal purpose, and frustration of 9 purpose. Match Group moves for summary judgment on KJ-Park’s claims for breach of contract 10 and breach of guaranty, as well on Match Group’s affirmative defenses of mistake and frustration 11 of purpose, and Match Group, LLC’s counterclaims for breach of contract and for monies had and 12 received. 13 II. LEGAL STANDARD 14 A motion for summary judgment should be granted if there is no genuine issue of material 15 fact and the moving party is entitled to judgment as a matter of law. Fed. R. Civ. P. 56(a); 16 Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 247-48 (1986). The moving party bears the initial 17 burden of informing the court of the basis for the motion, and identifying portions of the 18 pleadings, depositions, answers to interrogatories, admissions, or affidavits which demonstrate the 19 absence of a triable issue of material fact. Celotex Corp. v. Catrett, 477 U.S. 317, 323 (1986). In 20 order to meet its burden, “the moving party must either produce evidence negating an essential 21 element of the nonmoving party’s claim or defense or show that the nonmoving party does not 22 have enough evidence of an essential element to carry its ultimate burden of persuasion at trial.” 23 Nissan Fire & Marine Ins. Co., Ltd. v. Fritz Companies, Inc., 210 F.3d 1099, 1102 (9th Cir. 2000). 24 If the moving party meets its initial burden, the burden shifts to the non-moving party to 25 produce evidence supporting its claims or defenses. See id. at 1102. The non-moving party may 26

27 5 Although it maintains that it complied with all of its contractual obligations, KJ-Park does not 1 not rest upon mere allegations or denials of the adverse party’s evidence, but instead must produce 2 admissible evidence that shows there is a genuine issue of material fact for trial. See id. A 3 genuine issue of fact is one that could reasonably be resolved in favor of either party. A dispute is 4 “material” only if it could affect the outcome of the suit under the governing law. Anderson, 477 5 U.S. at 248-49. 6 III. DISCUSSION 7 A. KJ-Park’s Motion for Partial Summary Judgment6 8 KJ-Park contends that it constructed the base, shell, and core of the building in compliance 9 with all applicable laws, to the extent necessary for Match Group to be able to use the entire 10 building for general office use on all three floors. As such, KJ-Park argues that Match Group had 11 no basis to terminate the Lease, and that Match Group’s affirmative defenses based on mistake, 12 fraud in the inducement, illegal purpose, and frustration of purpose fail as a matter of law. KJ- 13 Park’s principal contention is that it obtained a common law vested right to use the entire building 14 for an office (with no retail) well before the parties entered into the Lease. See Dkt. No. 100 at 13. 15 1. Vested Rights Doctrine 16 KJ-Park has not demonstrated that the vested rights doctrine is relevant to delineate the 17 parties’ respective contractual rights and obligations under the Lease. Rather, caselaw indicates 18 that the doctrine is one that addresses legal rights and obligations as between KJ-Park and the 19 City. 20 Under the vested rights doctrine, “if a property owner has performed substantial work and 21 incurred substantial liabilities in good faith reliance upon a permit issued by the government, he 22 acquires a vested right to complete construction in accordance with the terms of the permit.” Avco 23 Cmty. Developers, Inc. v. S. Coast Reg’l Comm’n, 17 Cal. 3d 785, 791 (1976). The doctrine “is 24 grounded upon the constitutional principle that property may not be taken without due process of 25

26 6 Match Group objects to certain statements made by Mr. Minkoff and Mr. Fong in their respective declarations submitted in support of KJ-Park’s partial summary judgment motion. See 27 Dkt. No. 106 at 25. The Court finds it unnecessary to consider those particular statements in 1 law,” Russ Bldg. P’ship v. City & Cnty. of San Francisco, 44 Cal. 3d 839, 846 (1988), as well as 2 “estoppel of the governing body,” Anderson v. City Council of City of Pleasant Hill, 229 Cal. App. 3 2d 79, 89 (1964). “The doctrine of vested rights is ordinarily applied when a local agency 4 attempts to prevent the completion or use of a project on the grounds that the project, while lawful 5 at the time a permit was issued, had been rendered unlawful by an intervening change in the law.” 6 Attard v. Bd. of Supervisors of Contra Costa Cnty., 14 Cal. App. 5th 1066, 1076 (2017). Thus, 7 “[o]nce a landowner has secured a vested right the government may not, by virtue of a change in 8 the zoning laws, prohibit construction authorized by the permit upon which he relied.” Avco, 17 9 Cal. 3d at 791. 10 As KJ-Park acknowledged at the motion hearing (see Dkt. No. 122 at 35:23-36:6), there is 11 no precedent for invoking the vested rights doctrine in these circumstances against a private entity 12 based on the alleged misconduct or mistake by a government entity. KJ-Park’s theory of liability 13 as to Match Group for breach of the parties’ Lease and Guaranty rests principally, if not entirely, 14 on the City’s alleged misapplication of the Ordinance to bar or delay Match Group, LLC’s tenant 15 improvement plan which contemplated use of the subject property as office space on all three 16 floors of the building, contrary to KJ-Park’s alleged vested rights. See, e.g., Dkt. No. 102 ¶ 21, 17 Ex. 8 (KJ-Park correspondence with Match Group stating KJ-Park’s views regarding “erroneous 18 statement” by City employee and “delay caused solely and erroneously by the City of Palo Alto.”). 19 However, the correctness of the City’s application of the Ordinance to the subject property was 20 disputed as between KJ-Park and the City. There is no indication that the resolution of that 21 dispute was within Match Group’s control. KJ-Park points out that its correspondence with Match 22 Group noted general progress in discussions with the City, and that Match Group’s own internal 23 documents indicate that there was “[h]ope[] for decision from [the] City post Memorial Day 24 w[ee]k[en]d.” See Dkt. No. 110 ¶ 30, Ex. 21 at ECF 3; Dkt. No. 116 ¶¶ 3-5 & Ex. A at ECF 6, Ex. 25 B (Fong Dep. at 185:16-187:23), Ex. C. But nothing in the record states that KJ-Park and the City 26 would resolve their dispute by a date certain, or indicates that Match Group knew that a resolution 27 would ultimately be reached on June 4, 2019. 1 which to view the parties’ rights and obligations under the Lease, KJ-Park has not established that 2 it obtained a vested right to use of the building as office space on all three floors, by virtue of the 3 June 1, 2015 RLUA. While “[i]t is beyond question that a landowner has no vested right in 4 existing or anticipated zoning,” Avco, 17 Cal. 3d at 796, KJ-Park contends that, because the prior 5 property owner obtained the RLUA before the enactment of the Ordinance, when KJ-Park 6 subsequently purchased the property (more than eight months after the Ordinance was in effect), 7 KJ-Park obtained a vested right to construct and use the proposed building consistent with prior 8 zoning laws in effect at the time the RLUA issued. Although KJ-Park acknowledges that cases 9 generally recognize a building permit as the prerequisite for a vested rights claim, KJ-Park argues 10 that in Avco, “the California Supreme Court has acknowledged that a landowner may obtain a 11 vested right through a separate form of authorization, which provides substantially the same 12 specific description of the project and necessary discretionary approvals.” Dkt. No. 100 at 14-15. 13 KJ-Park argues that the June 1, 2015 RLUA was “a ‘functional equivalent’ to a building permit,” 14 inasmuch as the RLUA was based on detailed architectural drawings, reports, and presentations 15 showing office space on the ground floor, as well as on what KJ-Park says was a rigorous review 16 by the Architectural Review Board, and eventually by the City Council. See Dkt. No. 100 at 16; 17 Dkt. No. 101 ¶¶ 8-9, Exs. F & G. 18 In Avco, the California Supreme Court concluded that under the particular circumstances 19 presented, a grading permit was not sufficient to create a vested right to develop property where a 20 building permit was required, but the property owner failed to obtain one. Avco, 17 Cal. 3d at 21 791-97. Although the Avco decision was expressly not based on “an obdurate adherence to 22 archaic concepts inappropriate in the context of modern development practices or upon a blind 23 insistence on an instrument entitled ‘building permit,’” the California Supreme Court did not 24 definitively recognize an exception to the building permit rule. See Avco, 17 Cal. 3d at 797. 25 Rather, Avco left open the question of whether some other type of permit, if sufficiently specific, 26 could form an appropriate basis for a vested rights claim. See id. at 793-94, 797. Indeed, the Avco 27 court cautioned that if it were to expand the scope of permits on which developers could rely, 1 797. 2 KJ-Park does not cite any authority recognizing that an RLUA is the equivalent of a 3 building permit for purposes of establishing a vested rights claim. Moreover, the undisputed 4 evidence—including the terms of the RLUA and the Ordinance themselves—indicates that the 5 June 1, 2015 RLUA was not the final exercise of the City’s authority over the project, much less 6 the hallmark of the City’s final approval for use of the proposed building, which had not yet been 7 constructed. While Mr. Lait testified in deposition that the RLUA was the last discretionary 8 approval required for “the building shell and design,” the RLUA itself required KJ-Park to apply 9 for a building permit. See Dkt. No. 101 ¶ 3, Ex. A (Lait Dep. at 48:9-12, 17-23); Dkt. No. 101 ¶ 9, 10 Ex. G at 9; see also Consaul v. City of San Diego, 6 Cal. App. 4th 1781, 1798-99 (1992) (where 11 the relevant legal procedure “provides that further action, i.e., application for a building permit, is 12 required . . . [i]t makes no difference that building permit approval is normally considered a 13 ministerial process . . . ..”). The RLUA required that KJ-Park’s permit application should not only 14 be “in substantial conformance with plans received on October 16, 2014,” but should also be 15 modified to include the RLUA’s conditions of approval “and any additional conditions placed on 16 the project by the Planning Commission, Architectural Review Board, or City Council.” See Dkt. 17 No. 101 ¶ 9, Ex. G at ECF 9 (emphasis added). The RLUA also included “Additional Conditions” 18 and “Standard Conditions” that “[t]he approved use and/or construction are subject to, and shall 19 comply with, all applicable City ordinances and laws and regulations of other governmental 20 agencies.” See id. at ECF 32, 34; see also Aries Dev. Co. v. Cal. Coastal Zone Conservation 21 Comm’n, 48 Cal. App. 3d 534, 546 (1975) (“So long as the City retained discretion to approve or 22 disapprove the project, prior approval of the tentative map and site plan was not the final exercise 23 of the City’s authority over the project.”). Additionally, in deposition Mr. Lait drew a distinction 24 between the “architectural entitlement” approved by the RLUA, which concerned “the mass, the 25 size, [and] the scale” of the building, and the land uses for the proposed building, which “would be 26 subject to the permitted land uses of the zoning code.” See Dkt. No. 106-1 ¶ 9, Ex. 8 (Lait Dep. at 27 53:23-54:5). KJ-Park’s citation to San Clemente Estates v. City of San Clemente, 12 B.R. 209 1 (concluding that debtor had vested right to complete construction of subdivision based on, among 2 other things, reliance on a use permit and recordation of a final tract map). 3 Further, the undisputed evidence demonstrates that KJ-Park did not commence 4 construction or perform substantial work in reliance on any building permit before the November 5 2015 effective date of the Ordinance. Indeed, KJ-Park did not acquire the subject property until 6 more than eight months after the Ordinance went into effect. Dkt. No. 102 ¶ 2. KJ-Park did not 7 obtain the requisite building permit until January 2017, more than a year after the Ordinance went 8 into effect. Id. ¶ 9, Ex. 6. This sequence of events is significant because “neither the existence of 9 a particular zoning nor work undertaken pursuant to governmental approvals preparatory to 10 construction of buildings can form the basis of a vested right to build a structure which does not 11 comply with the laws applicable at the time a building permit is issued.” Avco, 17 Cal. 3d at 793 12 (emphasis added). “Following Avco, it is generally recognized that while the issuance of a permit 13 may insulate a party against subsequent changes in the law, it cannot create a vested right to 14 construct or use property in violation of laws in effect at the time of issuance of the permit.” 15 Attard, 14 Cal. App. 5th at 1077 (emphasis added). Additionally, the building permit itself says 16 nothing about allowing office space on all three floors of the proposed building. Rather, the 17 permit is for a “N[ew] W[arm] S[hell] F[or] T[hree] S[tory] C[ommercial] 23,853 S[quare] F[oot] 18 B[uilding], A[nd] B[elow] G[rade] P[arking] S[tructure].” Id.; Dkt. No. 102-6. As Mr. Reich’s 19 uncontradicted testimony demonstrates , a “warm shell” refers to a “building without the interior 20 tenant spaces built out” and no “specific occupancy.” Dkt. No. 106-1 ¶ 10, Ex. 9 (Reich Dep. at 21 104:15-21). 22 Nor is KJ-Park aided by the February 2017 email communications with City staff, 23 indicating that Mr. Lait did not feel that requiring retail use on the ground floor of the subject 24 premises would be reasonable. See Dkt. No. 101 ¶ 12, Ex. J at ECF 2; see also Dkt. No. 101 ¶ 3, 25 Ex. A (Lait Dep. at 82:18-23); Dkt. No. 101 ¶ 5, Ex. C (Reich Dep. at 65:5-21). There is no 26 evidence that either Mr. Lait, or any other individual City employee or official, had the authority 27 to make that determination. Other than a grandfathering provision that indisputably does not 1 adjustment” of the Ordinance requires action by the City Council. Dkt. No. 97-1 ¶ 4, Ex. 3 at 6. 2 While the parties argue at length about the proper interpretation of the settlement 3 agreement between KJ-Park and the City, and what the settlement agreement purportedly signifies 4 with respect to the City’s position on matters at issue here, that settlement agreement is irrelevant 5 to the existence of KJ-Park’s claimed vested right to use the subject building exclusively as an 6 office. Indeed, the settlement agreement itself states that “neither [KJ-Park nor the City] admits 7 any fault or wrongdoing, nor concedes that the legal or factual positions taken by the other Party 8 in this matter were correct.” Dkt. No. 101 ¶ 16, Ex. N at ECF 3. Even if the settlement agreement 9 were interpreted, contrary to this express language, as a concession that either KJ-Park or the City 10 was wrong, it would not matter for purposes of resolving the present motion for summary 11 judgment, as the City could not agree to the correctness of any legal conclusions in the present 12 proceedings. 13 Arguing that “‘there is no meaningful distinction between an estoppel claim and a vested 14 right claim where land use is at issue,’” Dkt. No. 100 at 14 (quoting Toigo v. Town of Ross, 70 15 Cal. App. 4th 309, 321 (1998), KJ-Park maintains that principles of equitable estoppel support the 16 existence of its alleged vested right to use the subject building as an office, with no retail. Here, 17 KJ-Park argues that following the issuance of the RLUA in 2015, the City could have enforced the 18 Ordinance with respect to the subject property. Instead, KJ-Park says, the City continued to give 19 approvals regarding the project, including by issuing a building permit and approving a 20 subsequent modification to the building’s façade, without stating or suggesting that KJ-Park could 21 not build and use all three floors of the building as office space, without retail. See Dkt. No. 100 22 at 16-19; Dkt. No. 114 at 9-10; Dkt. No. 102 ¶¶ 8, 9, 12, Exs. 4-7. However, the only relevant 23 actor for purposes of applying an estoppel in these circumstances is the City. See Attard, 14 Cal. 24 App. 5th at 1079 (“The elements of the doctrine are that (1) the party to be estopped must be 25 apprised of the facts; (2) he must intend that his conduct shall be acted upon, or must so act that 26 the party asserting the estoppel has a right to believe it was so intended; (3) the other party must be 27 ignorant of the true state of facts; and (4) he must rely upon the conduct to his injury.”). At the 1 See Dkt. No. 122 at 37. Emphasizing that the estoppel doctrine is based on concepts of equity and 2 fair dealing, see Raley v. Cal. Tahoe Reg’l Planning Agency, 68 Cal. App. 3d 965, 975 (1977), and 3 asserting that Match Group had at least constructive notice of the Ordinance when the parties 4 entered the Lease, KJ-Park maintains that estoppel applies here to prevent what it contends is the 5 unjust result of permitting Match Group to terminate the Lease based on the assertion that KJ-Park 6 was not in compliance with all laws. See Dkt. No. 100 at 16-19; Dkt. No. 114 at 9-10; Dkt. No. 7 122 at 37-38. KJ-Park’s position remains problematic because KJ-Park is using the rationale 8 underlying the estoppel doctrine as a legal theory to hold Match Group liable for the City’s 9 conduct. KJ-Park’s thesis is that because the City should have been estopped from applying the 10 Ordinance to the property, KJ-Park was in compliance with all laws, and Match Group did not 11 have a right to terminate the Lease. Proper application of estoppel principles in this context 12 requires that Match Group be estopped from terminating the Lease based on Match Group’s own 13 conduct, and not based on the City’s conduct, as to which there is no argument, evidence, or 14 suggestion that Match Group had any control. 15 KJ-Park is not aided by its reliance on Congregation ETZ Chaim v. City of Los Angeles, 16 371 F.3d 1122 (9th Cir. 2004). In Congregation ETZ Chaim, the Ninth Circuit concluded that the 17 plaintiff-congregation was entitled to equitably estop the defendant-city from revoking a building 18 permit, in view of the parties’ litigation history, a prior settlement agreement, and the defendant- 19 city’s post-settlement conduct. Congregation ETZ Chaim, 371 F.3d at 1124-25. Here, by 20 contrast, KJ-Park contends that Match Group was equitably estopped from terminating the Lease 21 because the City was wrong to have raised the Ordinance as a possible obstacle to Match Group’s 22 tenant improvement plans. The principle of equitable estoppel does not work this way; it is not a 23 catch-all doctrine that can be invoked to rectify a result a party believes is unfair. See Attard, 14 24 Cal. App. 5th at 1079-81 (declining to apply equitable estoppel where government entity 25 mistakenly issued a permit, contrary to law, even though plaintiff had invested over $550,000 in 26 reliance on the permit). 27 KJ-Park’s motion for partial summary judgment based on its claimed “vested legal right” 1 2. Match Group’s Third and Fourth Affirmative Defenses: Mistake 2 Match Group’s third and fourth affirmative defenses are based on unilateral mistake and 3 mutual mistake, respectively. Dkt. No. 76. KJ-Park maintains that these affirmative defenses fail 4 as a matter of law because “KJ-Park obtained a vested right to use the entire Property for office 5 use, with no retail requirement.” See Dkt. No. 100 at 22; see also Dkt. No. 114 at 15. KJ-Park’s 6 motion is denied for the reasons discussed above. 7 3. Match Group’s Sixth Affirmative Defense: Fraud in the Inducement 8 Match Group’s sixth affirmative defense alleges that KJ-Park “fraudulently induced 9 [Match Group] to enter into the Lease and the Lease Guaranty while [KJ-Park] represented to 10 [Match Group] that Match Group, LLC could lawfully use the entire premises for offices, when 11 [KJ-Park] knew that the City of Palo Alto had not granted the necessary approval or permit(s) for 12 the ground floor of the premises to be used for anything other than retail.” Dkt. No. 76 at 8. 13 Match Group further alleges that KJ-Park “made such false representations to [Match Group] with 14 actual knowledge and/or reckless disregard as to the truth of its representations, and with the intent 15 to induce Match Group, LLC to enter into the Lease and induce Match Group, Inc. to sign the 16 Lease Guaranty.” Id. 17 To the extent KJ-Park’s summary judgment motion regarding Match Group’s affirmative 18 defense of fraud in the inducement is based on the contention that KJ-Park had vested rights to use 19 the premises as office space on all three floors (with no retail), KJ-Park ‘s motion for summary 20 judgment is denied for the reasons stated above. 21 KJ-Park also contends that it is entitled to summary judgment on this affirmative defense 22 because there is no evidence that it intentionally misled Match Group when negotiating the Lease. 23 See Food Safety Net Servs. v. Eco Safe Sys. USA, Inc., 209 Cal. App. 4th 1118, 1131 (2012) (“To 24 establish a claim of fraudulent inducement, one must show that the defendant did not intend to 25 honor its contractual promises when they were made.”). Here, KJ-Park maintains that Match 26 Group cannot produce evidence of such intent, arguing that “undisputed evidence demonstrates 27 that KJ-Park received multiple assurances and approvals from the City indicating that it could use 1 the burden of proof on this affirmative defense, it has not addressed KJ-Park’s arguments. Match 2 Group instead refers the Court to defendants’ motion for summary judgment, which also does not 3 address their affirmative defense based on fraud in the inducement. See Dkt. No. 106 at 22-25; see 4 also generally Dkt. Nos. 97, 113. Elsewhere in its opposition papers (in connection with 5 arguments concerning other affirmative defenses), Match Group points to evidence that KJ-Park 6 was aware of the Ordinance before it purchased the subject property in 2016. See Dkt. No. 106 at 7 23 (citing Dkt. No. 97-1 ¶ 19, Ex. 18 at ECF 2-3). Although Match Group asserts that KJ-Park 8 withheld information about the Ordinance, Match Group cites only to Mr. Fong’s deposition 9 testimony that he could not recall, one way or the other, if KJ-Park informed Match Group about 10 the Ordinance during contract negotiations. See id. (citing Dkt. No. 97-1 ¶ 9, Ex. 8 (Fong Dep. at 11 90:12-18; 91:1-4)). Match Group also asserts that KJ-Park demonstrated a lack of candor in its 12 dealings with defendants, asserting that certain other evidence shows that in April 2019 KJ-Park 13 backdated an AIA Form G704 Certificate of Substantial Completion. See id. at 13; Dkt. No. 106- 14 1 ¶¶ 5, 6, Exs. 4, 5. Match Group has not persuasively demonstrated or articulated how this 15 evidence creates a genuine dispute of material fact regarding KJ-Park’s fraudulent intent at the 16 time the parties entered the Lease. 17 KJ-Park’s motion for summary judgment on Match Group’s sixth affirmative defense 18 based on fraud in the inducement is granted. 19 4. Match Group’s Seventh Affirmative Defense: Illegal Purpose 20 Match Group’s seventh affirmative defense alleges that “the subject Lease is unenforceable 21 because at all relevant times, the terms relating to [Match Group’s] intended exclusive use of the 22 subject building as office space violated the City of Palo Alto’s Retail Preservation Ordinance.” 23 Dkt. No. 76 at 8. California law defines “[u]nlawfulness” as that which is “[c]ontrary to an 24 express provision of law”; “[c]ontrary to the policy of express law, though not expressly 25 prohibited”; or “[o]therwise contrary to good morals.” Cal. Civ. Code § 1667. 26 KJ-Park argues that it is entitled to summary judgment on Match Group’s affirmative 27 defense of illegal purpose, based on the contention that KJ-Park had vested rights to use the 1 Park‘s motion for summary judgment as to Match Group’s seventh affirmative defense is denied. 2 5. Match Group’s Eleventh Affirmative Defense: Frustration of Purpose 3 Match Group’s eleventh affirmative defense alleges that “the express purpose of the Lease 4 was frustrated by the position that was taken by the City of Palo Alto up until [June] 4, 2019, that 5 the ground floor of the premises which were the subject of the Lease had to be used for retail 6 purposes, and that the Lease is therefore unenforceable on that basis.” Dkt. No. 76 at 9. 7 “A contract must be so interpreted as to give effect to the mutual intention of the parties as 8 it existed at the time of contracting, so far as the same is ascertainable and lawful.” Cal. Civ. Code 9 § 1636. “The doctrine of frustration excuses contractual obligations where performance remains 10 entirely possible, but the whole value of the performance to one of the parties at least, and the 11 basic reason recognized as such by both parties, for entering into the contract has been destroyed 12 by a supervening and unforeseen event.” SVAP III Poway Crossings, LLC v. Fitness Int’l, LLC, 13 87 Cal. App. 5th 882, 895 (2023) (cleaned up); see also Habitat Trust for Wildlife, Inc. v. City of 14 Rancho Cucamonga, 175 Cal. App. 4th 1306, 1336 (2009) (“[W]here performance remains 15 possible, but the reason the parties entered the agreement has been frustrated by a supervening 16 circumstance that was not anticipated, such that the value of performance by the party standing on 17 the contract is substantially destroyed, the doctrine of commercial frustration applies to excuse 18 performance.”). “A party seeking to escape the obligations of its lease under the doctrine of 19 frustration must show: (1) the purpose of the contract that has been frustrated was contemplated by 20 both parties in entering the contract; (2) the risk of the event was not reasonably foreseeable and 21 the party claiming frustration did not assume the risk under the contract; and (3) the value of 22 counter-performance is totally or nearly totally destroyed.” SVAP III Poway Crossings, LLC, 87 23 Cal. App. 5th at 895. “Governmental acts that merely make performance unprofitable or more 24 difficult or expensive do not suffice to excuse a contractual obligation.” Id. 25 To the extent KJ-Park’s summary judgment motion regarding Match Group’s affirmative 26 defense of frustration of purpose is based on KJ-Park’s contention that it had vested rights to use 27 the premises as office space on all three floors (with no retail), KJ-Park ‘s motion for summary 1 As an additional basis for its motion, KJ-Park contends that Match Group cannot show that 2 any delay in the City’s approval for Match Group, LLC’s occupancy and use of the subject 3 property as office space on all three floors was unforeseeable. Noting that the Lease expressly 4 excluded retail use (see Dkt. No. 97-1 ¶ 2, Ex. 1 at ECF 14), Match Group contends that the 5 fundamental purpose of the Lease was to use the entire building as office space (with no retail). 6 Match Group argues that this purpose “was commercially frustrated by the Ordinance such that 7 Match Group LLC could not use the space for its contracted purpose” and “had no certainty that it 8 would ever be able to use the space for its contracted use.” Dkt. No. 106 at 24-25. 9 Match Group has not demonstrated that the doctrine of commercial frustration fits the 10 particular facts presented here. The Lease provided Match Group with a discretionary right to 11 terminate the contract; Match Group was not obliged to terminate the Lease when it did. Dkt. No. 12 97-1 ¶ 2, Ex. 1 at ECF 8. Additionally, the Ordinance had been in effect for nearly three years 13 before the parties entered the Lease (see Dkt. No. 97-1 ¶ 4, Ex. 3), and the undisputed facts 14 indicate that at least two floors of the building remained available for Match Group’s use. Match 15 Group has not persuasively argued or demonstrated that the Ordinance itself was a “supervening 16 and unforeseen event,” or that the facts show that the value of the Lease was “substantially” or 17 “totally or nearly totally destroyed.” See SVAP III Poway Crossings, LLC, 87 Cal. App. 5th at 18 895; see also Habitat Tr. for Wildlife, Inc. 175 Cal. App. 4th at 1336. 19 KJ-Park’s motion for summary judgment on Match Group’s eleventh affirmative defense 20 based on frustration of purpose is granted. 21 B. Match Group’s Motion for Summary Judgment 22 Match Group moves for summary judgment on KJ-Park’s claims for breach of contract and 23 breach of guaranty, as well on as Match Group, LLC’s counterclaims for breach of contract and 24 for monies had and received, and Match Group’s affirmative defenses of mistake and frustration 25 of purpose. 26 1. KJ-Park’s Breach of Contract Claim 27 To prevail on a claim for breach of contract, a plaintiff must show (1) the existence of a 1 (3) defendants’ breach, and (4) resulting damages to plaintiff. Oasis W. Realty, LLC v. Goldman, 2 51 Cal. 4th 811, 821 (2011). Match Group contends that it is entitled to summary judgment on 3 KJ-Park’s contract claim on the ground that KJ-Park failed to provide the premises “in compliance 4 with Applicable Law (to the extent necessary for Tenant to obtain and retain a certificate of 5 occupancy or its legal equivalent for the Premises for general office use).” See Dkt. No. 97 at 5; 6 Dkt. No. 97-1 ¶ 2, Ex. 1 at ECF 8, 52. Match Group maintains that in view of the Ordinance, the 7 subject building could not have been legally used for “general office use” on all three floors until 8 June 4, 2019 (at the earliest) when the City Council returned from its closed session and resolved 9 questions concerning application of the Ordinance to the subject property. See Dkt. No. 97-1, ¶ 10 14, Ex. 13 at ECF 10. Match Group argues that the “Delivery Date,” as defined in the Lease, 11 therefore could not have occurred until after the March 1, 2019 deadline that triggered defendants’ 12 termination rights under the Lease. As such, Match Group contends that it properly terminated the 13 Lease pursuant to section 2.3 of the Lease. KJ-Park maintains that Match Group’s termination 14 was invalid and premature and that Match Group therefore breached the Lease. Arguing that it did 15 construct the “Base, Shell, and Core” of the building “in compliance with Applicable Law,” KJ- 16 Park disputes Match Group’s position that “delivery never timely occurred,” and that the 17 “Delivery Date” could not have occurred any earlier than June 4, 2019. See Dkt. No. 107 at 6. 18 KJ-Park’s opposition rests primarily on its alleged vested legal right to use of the building 19 as office space on all three floors (with no retail). See id. at 6-9. For the reasons discussed above 20 in connection with KJ-Park’s motion for partial summary judgment, KJ-Park’s alleged vested 21 legal right does not preclude summary judgment for Match Group on the breach of contract claim. 22 At the motion hearing, KJ-Park conceded that if the Court found no vested legal right, then 23 there would be nothing left to try with respect to KJ-Park’s claims regarding breach of the Lease 24 and breach of the Guaranty. See Dkt. No. 122 at 6 (“T[he] C[ourt]: And if I find there is no 25 vested legal right, then are we done from KJ-Park’s perspective or is there still an argument that 26 KJ-Park has that the lease was breach[ed] or the guaran[ty] was breached? M[s]. B[ellafronto]: 27 ‘Yeah. I think that—. . . we would concede that that would put the issue to rest, that we would be 1 Additionally, of material significance here is the fact that no one disputes that section 2.3 2 of the Lease identifies March 1, 2019 as the date that triggered Match Group’s right to terminate 3 the Lease “if the Delivery Date shall not occur on or before” that date. See Dkt. No. 97-1 ¶ 2, Ex. 4 1 at ECF 8; see also Dkt. No. 97 at 15; Dkt. No. 107 at 5 n.1. KJ-Park disputes Match Group’s 5 position that the “Delivery Date” could not have occurred before June 4, 2019. KJ-Park devotes 6 much of its briefing to arguments about the relevance and proper interpretation of the settlement 7 agreement between KJ-Park and the City, and the legal import of the City Council’s June 3, 2019 8 closed session. See Dkt. No. 107 at 9-16. However, KJ-Park has not presented evidence or 9 argument demonstrating (or at least raising a triable question) that the “Delivery Date” occurred 10 on or before the March 1, 2019 trigger date for Match Group’s termination rights. 11 Accordingly, Match Group’s motion for summary judgment on KJ-Park’s claim for breach 12 of the Lease is granted. 13 2. KJ-Park’s Breach of Guaranty Claim 14 As Match Group is entitled to summary judgment on KJ-Park’s claim for breach of the 15 Lease, the Court also grants Match Group’s motion for summary judgment on KJ-Park’s claim for 16 breach of the Guaranty. See Gerristen v. Warner Bros. Entm’t, Inc., 112 F. Supp. 3d 1011, 1035 17 (C.D. Cal. 2015) (“California courts apply the same [breach of contract] legal standard to breach 18 of guaranty claims.”); Harrison Ventures, LLC v. Alta Mira Treatment Ctr., LLC, No. C10-00188 19 RS, 2010 WL 1929566, at *5 (N.D. Cal. May 12, 2010) (dismissing claim for breach of guaranty 20 that depended upon a claim for breach of contract, where plaintiff failed to state sufficient facts 21 supporting breach of underlying contract); Cal. Civ. Code §§ 2787, 2809, 2810; see also Dkt. No. 22 122 at 6. 23 3. Match Group’s Third and Fourth Affirmative Defenses: Mistake 24 Match Group’s third affirmative defense alleges that KJ-Park’s claims for breach of the 25 Lease and of the Guaranty are barred by unilateral mistake “because [KJ-Park] [led] [Match 26 Group] to believe, and [Match Group] w[as] under the mistaken impression, that [Match Group] 27 could use the entirety of the premises that were the subject of the Lease for offices.” Dkt. No. 76 1 w[as] under the mistaken impression that they could lawfully use the entirety of the Premises for 2 offices, and [KJ-Park] took advantage of it.” Id. at 7. Match Group contends that “Match group, 3 Inc. would not have signed the Lease Guaranty if [it] had known that Match Group, LLC could not 4 lawfully use the entire premises exclusively as office space.” Id. 5 Match Group’s fourth affirmative defense is based on mutual mistake and alleges that 6 “both [KJ-Park] and [Match Group] were under the mistaken impression when they entered into 7 the Lease that [d]efendants could use the entirety of the premises that were the subject of the 8 Lease for offices.” Id. Match Group further alleges that “[n]either party was aware at the time 9 they entered into the Lease that the City of Palo Alto took the position that the City’s Retail 10 Preservation Ordinance precluded [d]efendants from lawfully using the ground floor of the 11 Premises for offices.” Id. Match Group contends that “neither party would not have entered into 12 the Lease, and Match Group, Inc. would not have signed the Lease Guaranty, if [it] had known 13 that Match Group, LLC could not lawfully use the entire premises exclusively as office space.” 14 Id. 15 Separate and apart from the issue of whether Match Group properly terminated the Lease, 16 Match Group moves for summary judgment principally upon its third affirmative defense based on 17 unilateral mistake. Match Group moves, in the alternative, for summary judgment on defendants’ 18 fourth affirmative defense based on mutual mistake. Dkt. No. 97 at 17-19. Match Group contends 19 that at the time the parties entered the Lease, Match Group was unaware of the “Ordinance and its 20 application” to the subject property, and that this was a unilateral “mistaken fact in the context of 21 the Lease and Guarant[y],” in view of the Lease terms stating that KJ-Park would construct a 22 building “in compliance with Applicable Law” and expressly prohibiting “any retail or restaurant 23 use that serves the general public[.]” Dkt. No. 97-1 ¶ 2, Ex. 1 at ECF 14, 52. 24 A party may rescind a contract if the rescinding party’s consent to the contract was given 25 by mistake. Cal. Civ. Code § 1689(b)(1); Donovan v. RRL Corp., 26 Cal. 4th 261, 278 (2001). A 26 mistake may either be one of fact or law. A mistake of fact is “a mistake, not caused by the 27 neglect of a legal duty on the part of the person making the mistake,” and consists of (1) “[a]n 1 (2) [b]elief in the present existence of a thing material to the contract, which does not exist, or in 2 the past existence of such a thing, which has not existed.” Cal. Civ. Code § 1577. “‘A mistake of 3 law is when a person knows the facts as they really are, but has a mistaken belief as to the legal 4 consequences of those facts.’” Estate of Eskra, 78 Cal. App. 5th 209, 221-22 (2022) (quoting 5 Hedging Concepts, Inc. v. First Alliance Mortgage Co., 41 Cal. App. 4th 1410, 1421 (1996)). A 6 mistake of law “constitutes a mistake, within the meaning of [California law] only when it arises 7 from” (1) “[a] misapprehension of the law by all parties, all supposing that they knew and 8 understood it, and all making substantially the same mistake as to the law” or (2) “[a] 9 misapprehension of the law by one party, of which the others are aware at the time of contracting, 10 but which they do not rectify.” Cal. Civ. Code § 1578. 11 To the extent KJ-Park relies on its alleged “vested legal right” to use the entire building as 12 office space (with no retail), that contention does not preclude summary judgment for Match 13 Group on its affirmative defense of mistake. 14 Regardless of whether Match Group’s claimed mistake is labeled one of fact or law, the 15 record before the Court is not sufficiently developed for the Court to determine whether Match 16 Group is entitled to summary judgment. The parties’ briefing does not clarify matters. Match 17 Group essentially contends that at the time of the parties’ contract negotiations, it did not know 18 about the Ordinance; KJ-Park was aware of the Ordinance; the Lease prohibited retail use; and in 19 deposition Mr. Fong could not recall one way or the other whether KJ-Park informed Match 20 Group about the Ordinance. See Dkt. No. 97-1 ¶¶ 6, 9, 19, Ex. 5 (Perez Dep. at 83:19-21, 84:6-7); 21 Ex. 8 (Fong Dep. at 90:12-18; 91:1-4)); Ex. 18. The record suggests that there are material 22 disputes about what mistakes may have been made, and by whom; whether KJ-Park knew about 23 Match Group’s claimed mistake; and whether the parties may have made different mistakes of fact 24 and/or law. 25 Match Group’s motion for summary judgment on its affirmative defenses of unilateral and 26 mutual mistake is denied. 27 4. Match Group’s Eleventh Affirmative Defense: Frustration of Purpose 1 judgment, Match Group’s motion for summary judgment on its eleventh affirmative defense based 2 on frustration of purpose is denied. 3 5. Match Group, LLC’s Counterclaims 4 Match Group, LLC’s counterclaim for breach of contract essentially alleges that KJ-Park 5 failed to deliver the premises in the condition required under the Lease, that Match Group properly 6 terminated the Lease, and that section 2.3 of the Lease requires KJ-Park to return $300,000, as 7 well as “any additional rent or security,” Match Group says it paid to KJ-Park. Dkt. No. 76 at 11- 8 12. 9 Match Group, LLC’s related counterclaim for monies had and received alleges that KJ- 10 Park “is indebted to [Match Group, LLC] in a certain sum for money had and received by [KJ- 11 Park] for the use of Match Group, LLC—namely, all sums received from [Match Group, LLC] for 12 rent, expenses, vendor costs and security regarding subject Premises (which sums exceed 13 $300,000).” Id. at 12. Match Group, LLC further alleges that KJ-Park “never delivered the 14 subject Premises in the condition as was required under the Lease,” and that KJ-Park “received 15 such sums from [Match Group, LLC] which in equity should be paid over to [Match Group, 16 LLC].” Id. 17 For the reasons discussed above, Match Group is entitled to summary judgment that it 18 properly terminated the Lease pursuant to section 2.3 of the Lease. Pursuant to section 2.3, upon 19 Match Group’s termination of the Lease, the Lease “shall terminate, and Landlord and Tenant 20 shall have no further obligations or liabilities under the Lease (other than those stated in this Lease 21 to survive the expiration date) except Landlord shall promptly return to Tenant any rent, additional 22 rent or security paid by Tenant to Landlord.” Dkt. No. 97-1 ¶ 2, Ex. 1 a ECF 8. KJ-Park has not 23 raised a triable issue of fact regarding whether, upon Match Group’s May 30, 2019 termination of 24 the Lease, section 2.3 of the Lease requires KJ-Park to return “any rent, additional rent or security 25 paid by Tenant to Landlord.” However, the Court is unable to grant summary judgment for Match 26 Group, LLC on these counterclaims, inasmuch as Match Group, LLC has not submitted evidence 27 documenting the sums it claims to have paid to KJ-Park that KJ-Park reportedly has not returned 1 record such evidence may be found. See Dkt. No. 97 at 21 (requesting judgment “total[ing] at 2 least $300,000, since May 30, 2019.”). 3 Accordingly, insofar as it appears that the sum of money claimed by Match Group, LLC 4 || remains to be tried, Match Group’s motion for summary judgment on its counterclaims is denied 5 to that extent. 6 || IV. CONCLUSION 7 Based on the foregoing, the Court grants in part and denies in part KJ-Park’s motion for 8 || partial summary judgment, and grants in part and denies in part Match Group’s motion for 9 summary judgment. 10 IT IS SO ORDERED. 11 Dated: September 3, 2024 12 Virginia K. DeMarchi 13 United States Magistrate Judge

15 16

= 17

Z 18

19 20 21 22 23 24 25 26 27 28